Skip to content

Menu

MATTHEW J. DEVRIES of Buchalter, A Professional Corporation
HomeAboutContactSpeaking
Search
Close

Best Practices Construction Law

Meet Matt
Free Resources
Top Posts
Speaking

time extension

Subscribe to time extension via RSS

Slow As A Turtle? Florida Court Finds “No Damages for Delay” Clause Has Limits

By Matthew DeVries on June 22, 2022
Posted in Case Law, Regional Construction

My commute home last night took longer than usual. It was not excessive traffic, an accident, or a stalled car.  Rather, the cause of my delayed commute was a turtle: one single turtle crossing the road, holding up about 30 cars for what seemed like an eternity. (Never mind the fact that no one got…

MATTHEW J. DEVRIES

About this Blog

Problems and solutions. That’s what I discuss on this blog. Sign up to receive updates by email and receive my popular ebook on practical construction solutions.

Sign Up

Privacy: Single dad of seven kids. Don’t have time to share your email address. And I won’t.

Stay Connected

Subscribe to my blog via RSS View My LinkedIn Profile My Facebook Profile Instagram

Resources

  • Construction
  • Construction Law Update
  • Design Cost Data Magazine
  • Leadership & Balance
  • Modern Contractor Solutions
  • Social Media

Topics

Archives

Recent Upates

  • New Tools, Streamlined Access: AAA’s Website Gets a Major Redesign
  • When Delays Cost More Than Time: Understanding Consequential Damages
  • Drone Delivery Takes Off: Contractor Serves Subcontractor with Default Notice via Drone
  • Insurance and Reconstruction: A Guide for Property Owners Facing Wildfire Aftermath and Other Disasters
  • OMG! Bruh 86s PLAs Under CICA—It’s a “W” for Fed Contractors!

Links

  • AGC of America
  • American Arbitration Association
  • American Institute of Architects
  • American Subcontractors Association
  • Associated Builders & Contractors
  • Construction Risk.com
  • Design Build Institute of America
  • Konstructr
  • U.S. Green Building Council
Published by
Matthew J. DeVries
Matthew J. DeVries logo

Stay Connected

Subscribe to my blog via RSS View My LinkedIn Profile My Facebook Profile Instagram
Privacy PolicyDisclaimer

Buchalter Offices

Nashville|Atlanta|Portland|Chicago|Sacramento|Denver|Salt Lake City|Los Angeles|San Diego|St. Helena|San Francisco|Scottsdale|Orange County|Seattle
Copyright © 2025, Matthew J. DeVries. All Rights Reserved.
Law blog design & platform by LexBlog LexBlog Logo